Roofing Contract Template

Build Roofs, Build Trust: Customize roofing contracts that protect your business, set expectations, and ensure smooth project completion from start to finish.

Uploading Image...

Tradewinds Housing
Roofing Contract
Jim Clark Co
Roofing Contract
Jim Clark Co

Agreement

This Roofing Contract ("Agreement") is made and entered into on [Date], by and between:
Participants
Client

John Doe

123 Main St

New York, Ny 10012

[email protected]

(212) 555-1212

Contractor

Jessica Clark

3445 Ravenwood Dr

College Park, GA 30349

[email protected]

(404) 763-3294
Terms
1. Project Timeline:

Start Date:
End Date:
Work Schedule: Work will commence daily at [Start Time] and end at [End Time], except on weekends and public holidays unless otherwise agreed.
Contingencies: In the event of bad weather or other unforeseen circumstances, the project timeline may be adjusted. The Contractor will notify the Client as soon as possible of any delays.

2. Property Description: [Full legal description of the property where the work will take place]

3. Grant of Access: The Client grants the Contractor and their employees the right to access the property at [Client's Address] for the purpose of performing the roofing services described in this Agreement.

4. Right to Inspect:

The Client retains the right to inspect the work performed by the Contractor at any reasonable time to ensure compliance with the terms of this Agreement.
All required inspections by law, including building inspections, will be scheduled and completed as necessary.

5. Scope of Work: The Contractor agrees to perform the following roofing services (the "Services") for the Client:

[Detailed description of the roofing services, including removal of old roofing materials, installation of new roofing materials, and any other relevant tasks]
Work Hours: Work will start each day at [Start Time] and end at [End Time].
Safety Procedures: The Contractor will adhere to all safety regulations and standards while performing the Services.
Waste Disposal: The Contractor will be responsible for the disposal of all waste materials generated during the project. Disposal will be handled in compliance with local regulations.

6. Materials:

Materials List: [Detailed list of all materials required for the project]
Payment for Materials: The Client [will/will not] be responsible for the cost of materials. If the Client is responsible, the Contractor must obtain prior approval for any additional materials not listed.

7. Price and Payment Schedule:

Total Price: The total cost for the roofing services is [Total Amount].
Payment Schedule: Payments will be made according to the following schedule: [Specify payment amounts and due dates, e.g., deposit upon signing, percentage upon completion of milestones, final payment upon completion]
Late Fees: A late fee of [Amount] will be charged for any payment not received within [specify number of days, e.g., 5 days] of the due date.

8. Permits, Licensing, and Insurance:

Building Permit: The Contractor will obtain and pay for all necessary building permits.
Licensing and Insurance: The Contractor will maintain appropriate licenses and insurance, including worker’s compensation insurance and general liability insurance. The Contractor will provide proof of insurance to the Client upon request.
Homeowner’s Insurance: The Client agrees to maintain homeowner’s insurance covering the property during the roofing project.

9. Amendments and Termination:

Amendments: This Agreement may be amended only by a written document signed by both parties. Any changes must be discussed and agreed upon by both parties before they take effect.
Termination: Either party may terminate this Agreement with [specify notice period, e.g., 30 days] written notice. Termination for cause can occur immediately if either party breaches any material provision of this Agreement and fails to cure such breach within [specify period, e.g., 10 days] after receiving written notice of the breach.

10. Warranties:

List of Warranties: [Detailed list of all warranties provided by the Contractor, including duration and coverage]
Optional Warranties: [List and cost of any optional warranties available to the Client]

11. Dispute Resolution: Any disputes arising under this Agreement shall be resolved through the following procedures:

Negotiation: The parties will first attempt to resolve the dispute through informal negotiation.
Mediation: If the dispute cannot be resolved through negotiation, the parties agree to attempt to resolve the dispute through mediation.
Arbitration: If the dispute is not resolved through mediation, it will be submitted to binding arbitration under the rules of the [specify arbitration association, e.g., American Arbitration Association].
Legal Remedies: The parties agree that the arbitrator's decision will be final and binding and may be entered as a judgment in any court of competent jurisdiction.

13. Signatures: By signing below, the parties agree to the terms and conditions outlined in this Roofing Contract.

This Agreement constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, or agreements, whether written or oral. This Agreement may be executed in counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument.
Signatures
Click to sign

John Doe

Click to sign

Jessica Clark

Expand Document

Use this Template

PDF

Word

ODT

What is a Roofing Contract?

Whether you're a homeowner finally fixing that leak-prone roof or a contractor tackling your next project, taking the time to truly understand a roofing contract sets everyone up for success. A contract not only outlines the work and payment details but also protects both parties involved. Let's look at what a roofing contract should include and tips for using one effectively,

A roofing contract is a blueprint that clearly spells out the details between the contractor and the customer - it lays out specifics of the work, materials, timeline, and cash flow in black and white. Don't just trust a handshake - protect yourself with clear expectations up front.

Tips for Using a Roofing Contract

Once you've got a draft, use these pro tips to polish your contract game:

Be crystal clear on the work: Don't leave room for confusion - list the types of materials to be used and any specific techniques or brands preferred. Include any preparatory work, cleanup, and disposal of materials. Making sure this part is clear will help avoid confusion and make sure the project turns out the way the client wants.
Build in wiggle room for negotiations: Stuff comes up, like material choices, project timelines, or even budget adjustments, so allow some flexibility for changes without rewriting the whole contract.
Discuss the payment options. When does the contractor get their deposit? Is the final payment due upon completion? Payment terms should be clearly outlined in the contract. This includes the total cost, payment milestones (e.g., deposit, progress payments, final payment upon completion), and accepted payment methods. Having easy-to-understand payment rules can help the contractor know when they'll get paid and keep the money flowing smoothly.

Types of Roofing Contracts

There are many different kinds of roofing agreements that are made to fit the specific needs of each project. Depending on the job, you may use:

Fixed price contracts (the contractor agrees to one lump sum).
Time and materials (payments based on hours worked and materials used).
Cost plus (the customer will pay for the materials plus extra to cover the contractor's overhead and profit).

Key Terms Needed in a Roofing Contract

The ultimate contract checklist includes:

Parties Involved: Contact info for the contractor and the customer.

Scope of Work: This is a project roadmap and should include the type of roofing work (e.g., repair, replacement, or installation), the materials and brands to be used, and any specific techniques that will be applied. A detailed scope of work ensures both parties are on the same page and have a roof that looks sharp and functions flawlessly.

Project Duration: This section shows a roadmap for the project, including:

Start & Finish Dates: The expected start and completion dates for the new roof.
Weather or Not: Mother Nature can sometimes disrupt the schedule. This clause acknowledges that weather delays may occur.

Cost and Payment Terms: The contract should outline the project cost, with breakdowns for materials and labor. It should also detail the payment schedule, including any deposit required, potential progress payments as the work progresses, and the final payment due upon completion. List accepted payment methods, e.g., cash, check, credit card.

Warranties: Describe the warranties provided by both the material manufacturer and the contractor. Include the length of these warranties and what they cover. Make sure to include the process for claiming a warranty.

Insurance and Licenses: Before the customer signs, this section ensures the contractor has the necessary licenses and insurance. That means:

Liability Insurance: Protects the customer from financial responsibility if something gets damaged during the project.
Worker's Compensation Insurance: This protects the contractor from financial responsibility in case of employee injuries on the job.

This double layer of protection gives the customer peace of mind, knowing their project is in safe hands.

Permits and Approvals: State who is responsible for getting any necessary permits and making sure the project building follows the local building codes. It's like getting the thumbs up from the building officials before the work begins!

Change Orders: Things can change! This clause outlines how to handle adjustments to the original agreement.

Making Changes: Both the customer and the contractor need to agree on any modifications in writing.
Cost & Timeline Impact: Any changes will likely affect the project's price and completion date. This clause ensures these adjustments are clearly documented and communicated to everyone involved.

Remember, clear communication is key! Discussing changes openly helps avoid surprises and keeps the project on track.

Site Conditions and Access: Before the hammers fly, this section details two key things:

Documentation of the existing condition of the roof, its current materials, and any visible damage.
An outline of how the contractor will safely access the property and the roof throughout the project.

Cleanup and Disposal: Make sure to include who will clean up and get rid of the old roofing stuff and any trash made during and after the project.

Termination Clause: Life throws curveballs! This clause outlines when the homeowner or the contractor can call it quits. Clearly outline any payment obligations, like outstanding balances or early termination fees.

Dispute Resolution: Let's hope things run smoothly, but disagreements can happen. This clause outlines how to resolve them:

Mediation (optional): A neutral third party helps both parties reach an agreement.
Arbitration (optional): A neutral third party makes a binding decision, like a judge (but usually faster and cheaper).
Legal Action (last resort): If all else fails, courts settle the dispute.

Tip: Consider including a clause that requires trying mediation or arbitration before going to court. It can save time and money!

Signature and Date: Both the contractor and the customer need to sign and date the contract to make it official. It's a binding agreement that protects everyone involved.

By including these essentials, you cover your butt and smooth out the process. The customer feels secure, and the contractor gets paid - it's a total win-win.

Roofing Warranties

Duration of Roofing Warranties

Manufacturers back their materials with guarantees. Here's a quick guide to roofing material warranties:

Asphalt Shingles: Expect coverage between 15-30 years, with some premium brands boasting lifetime warranties!
Metal Roofing: These roofs are built to last, with warranties typically lasting 20-50 years.
Tile & Slate: The ultimate in durability, tile and slate warranties can extend up to a whopping 50 years!

Workmanship Warranty: This protects the customer from faulty installation. Warranties vary by contractor but typically range from 1-10 years. Top-notch companies might offer even longer coverage based on their confidence in their work.

What Roofing Warranties Do Not Cover

Damage due to Acts of God: Hurricanes, tornadoes, earthquakes - these extreme events are usually excluded from warranties.
Roof Neglect: Regular maintenance is key! Most warranties require it, and skipping it could void coverage.
DIY Disasters: Unless the contractor is approved by the warranty provider, any repairs or modifications made can void the warranty.

Insurance for Contractors

Roofing contractors should carry two main types of insurance:

Liability Insurance: Protects the contractor if someone gets hurt or property is damaged during the work.
Worker's Compensation Insurance: Covers the contractor's employees in case of injuries on the job.

Licensing Requirements

A roofing license depends on location, which varies by state.

Specific Roofing License: Some states require a dedicated roofing contractor license.
General Contractor's License: Other states allow roofing work under a general contractor's license.

Getting Licensed: The process typically involves passing an exam, demonstrating financial stability, and having proper insurance.

Streamline with Online Roofing Contract Templates

Using an online platform like Butterscotch to create, send, and sign roofing contracts online can transform your business. Customizable templates mean you spend less time prepping paperwork and more time building strong relationships with your clients.

. Here's how:

Streamlined Signing: Get those electronic signatures in a flash!
Effortless Edits: Need to tweak something? Online contracts make revisions effortless.
Contract Tracking Made Easy: Always know where your contract stands with clear status updates.
Legal Peace of Mind: Ensure everything is documented and accessible, keeping you on the right side of the law.

Butterscotch makes managing roofing contracts faster, easier, and more secure. So ditch the paper chase and embrace the digital world!

Butterscotch Contracts