Flooring Contract Template

Lay the Groundwork: Create professional flooring contracts that define services, secure terms, and ensure smooth installations from start to finish.

Uploading Image...

Flooring Contract
Jim Clark Contractors
Flooring Contract
Jim Clark Co.

Agreement

This Flooring Installation Contract ("Agreement") is made and entered into on [Date], by and between:
Participants
Property Owner

John Doe

123 Main St

New York, Ny 10012

[email protected]

(212) 555-1212

Flooring Contractor

Jim Clark

3445 Ravenwood Dr

College Park, GA 30349

[email protected]

(404) 763-3294
Terms
1. Property Description: The flooring installation will take place at the following location: [Legal Description of the Property, including address].

2. Grant of Access: The Property Owner grants the Flooring Contractor and any subcontractors access to the property to perform the agreed-upon flooring installation work. Access will be granted during the following days and times: [Specify days and times]. Tools, materials, and equipment may be stored in the following locations: [Specify locations and procedures].

3. Right to Inspect: The Property Owner retains the right to inspect the work at any reasonable time to ensure compliance with the terms of this Agreement.

4. Scope of Work:

The Flooring Contractor agrees to perform the following flooring installation work:

Flooring Type: [Specify the type of flooring to be installed, e.g., hardwood, laminate, tile, carpet].
Materials: [Specify who will order and purchase the flooring and other necessary materials, e.g., The Property Owner will order and purchase the materials, or The Flooring Contractor will supply all materials].
Installation Details: [Include any relevant details about the installation process, such as underlayment, subfloor preparation, etc.].
Cleanup: The Contractor will be responsible for cleaning up the work area after the installation is complete.

5. Project Timeline:

Installation Start Date:
Expected Completion Date:
Project Timeline: The project will follow this timeline: [Provide a detailed timeline with milestones and deadlines].

6. Price and Payment Terms:

Total Project Price:
Deposit:
Payment Schedule: Payments will be made as follows: [Specify payment schedule, e.g., deposit upon signing, milestone payments, balance upon completion].
Payment Methods: Acceptable methods of payment include [specify methods, e.g., check, bank transfer, credit card].
Late Payment Policy: Late payments will incur a fee of [specify amount or percentage].
Lien Policy: The Flooring Contractor reserves the right to file a lien on the property for any unpaid balance after [specify period, e.g., 30 days] from the due date.

7. License, Permit, and Insurance Requirements:

Licenses and Permits: The Flooring Contractor will obtain all necessary licenses and permits to perform the work.
Insurance: The Flooring Contractor will maintain appropriate insurance coverage, including general liability and workers' compensation insurance. Proof of insurance will be provided to the Property Owner upon request.

8. Unforeseen Circumstances/Acts of God: Neither party will be held liable for failure to perform their obligations under this Agreement due to unforeseen circumstances or acts of God (e.g., natural disasters, severe weather, pandemics).

9. Hidden Defects: If the Flooring Contractor discovers any hidden defects or hazardous conditions (e.g., mold, asbestos, subfloor issues) during the installation, work will be halted immediately, and the Property Owner will be notified. The parties will then agree on the necessary repairs and any additional costs or changes to the timeline.

10. Amendments: This Agreement may be amended only by a written document signed by both parties. Any changes must be discussed and agreed upon before they take effect.

11. Termination:

By Either Party: Either party may terminate this Agreement with [specify notice period, e.g., 30 days] written notice.
For Cause: Either party may terminate this Agreement immediately if the other party breaches any material provision and fails to cure such breach within [specify period, e.g., 10 days] after receiving written notice of the breach.

12. Warranties:

The Flooring Contractor provides the following warranties for the work performed:

Workmanship Warranty: [Specify duration and coverage of the warranty, e.g., 1-year warranty on workmanship].
Materials Warranty: [Specify any warranties on materials, if applicable].

13. Dispute Resolution and Remedies:

Negotiation: The parties will first attempt to resolve disputes through informal negotiation.
Mediation: If negotiation fails, the parties agree to attempt mediation.
Arbitration: If mediation fails, disputes will be resolved through binding arbitration under the rules of the [specify arbitration association].
Governing Law: This Agreement will be governed by the laws of the state of [specify state].

14. Indemnification: Each party agrees to indemnify and hold harmless the other party from any claims, damages, or liabilities arising out of the performance of this Agreement, except in cases of gross negligence or willful misconduct.

15. Attachments:

The following documents are attached to and form part of this Agreement:

Blueprints: [List any blueprints attached]
Diagrams: [List any diagrams attached]
Spec Sheets: [List any spec sheets attached]
Other Attachments: [List any other relevant documents attached]

16. Signatures: By signing below, the parties agree to the terms and conditions outlined in this Flooring Installation Contract.

This Agreement constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, or agreements, whether written or oral. This Agreement may be executed in counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument.
Signatures
Click to sign

John Doe

Click to sign

Jim Clark

Expand Document

Use this Template

PDF

Word

ODT

Level Up Your Flooring Project with a Solid Contract

Let's talk flooring contracts. We know they're not the most exciting thing, but laying floors with a solid contract is a game-changer. It's a safety net that ensures everyone's on the same page and protected from potential drama.

A flooring contract helps:

Keep contractors and clients safe from misunderstandings.
Spell out the scope of work, materials, costs, and timelines.
Avoid costly surprises down the line.

Not sure where to start? We'll cover what a flooring contract is, why you need one, and go over how to create a flooring contract using a template. Let's dive in!

What is a Flooring Contract?

So, what is a flooring contract? In a nutshell, it's an agreement between the client and the flooring contractor. This document is like a project blueprint, outlining details like, what type of flooring is getting installed, the materials being used, the project timeline, and the costs involved.

Think of a flooring contract as a way to establish communication, avoid costly misunderstandings, and keep everyone on the same page. That way, you’ll be able to enjoy those beautiful new floors even more.

What Job Types Would Require a Flooring Contract?

Let's face it, flooring projects can get messy (and we're not just talking about the demolition phase!). That's why a solid contract is essential for:

Residential Flooring Installation: Installing new floors in a residential space? A contract ensures the homeowner knows exactly what they're getting (and what they're paying for!).
Commercial Flooring Projects: Large-scale projects like installing carpet in an office building or vinyl flooring in a retail space require detailed contracts to keep everything on track (and on budget!).
Flooring Repairs and Renovations: Even small jobs, such as repairing damaged sections of flooring or renovating existing floors, should be covered by a contract to lay out the work and costs involved.
Custom Flooring Jobs: Intricate tile patterns or specialty materials? A contract helps bring unique visions to life and ensures everyone's on the same wavelength!

What Are Some Common Terms of a Flooring Contract?

Here’s some common sections and terms you’ll probably see in a flooring contract:

Scope of Services: This section should cover the details of the job, like where the new flooring will go (which rooms, areas, etc) and services such as prepping the subfloor for new flooring, removing the old flooring, levelling the floor, and moisture testing the subfloor.
Materials: This section outlines who’s responsible for buying the materials, and has a detailed list of all the materials needed for the job, including the type of flooring, flooring color and style, the brand and product names, as well as the quantity needed (exact amount or square footage).
Installation Method:The installation method will be described here.
- Here are some common installation methods:
  - Glue-down: a strong bond between flooring and subfloor
  - Floating: a cushioned installation for a smoother feel
  - Nail-down: a secure fastening for maximum durability
Timeline: Outlines a timeline for the project from start to end, and should have a plan for for unexpected challenges like bad weather or supply chain hiccups.
Payment Terms: There needs to be a clear payment plan that suits everyone. Think about upfront costs, milestone payments, the final bill, and which payment methods are accepted.
Warranties: Include any warranties or guarantees that come with the materials or the installation. This helps protect the client in case of defects or poor workmanship.
Cleanup and Disposal: Make clear who's responsible for cleaning up the workspace, and disposing of waste materials like old flooring, packaging, and other debris.
Permits and Approval: Let's talk about red tape. Include who is in charge of getting any necessary permits or approvals from local authorities for this project.
Liability and Insurance: Let's cover our bases by including the contractor's insurance coverage. And who's responsible if something gets damaged or someone gets hurt during the project?

Should I Include an Estimate?

Let's be upfront about the cost. A detailed estimate gives your client a clear picture of what they're in for. It breaks down labor, materials, and any extras. No surprises, just transparency.

Here are some tips for including an estimate in your flooring contract:

Be Detailed: Let's be crystal clear about the costs. Break down estimates into categories, like materials, labor, and extra services. Transparency shows your client you're upfront and honest.
Allow for Adjustments: Life's full of surprises, and so are flooring projects! Include a clause that allows for estimate adjustments if unexpected costs pop up. This prevents disputes and keeps the project on track.
Attach to the Contract: Make it official by attaching the estimate to the contract. This can be as an appendix or within the payment terms section. This way, it's clear that the estimate is part of the legally binding agreement.

Stick to these guidelines, and you'll create an estimate that's clear, detailed, and easy for your client to understand. This will help set your project up for success!

Get Started On Your Flooring Contract With Butterscotch

Ready to make your flooring projects a whole lot smoother? Now, here’s where the magic happens. Butterscotch has customizable templates to make life easier. Why you'll love Butterscotch:

Templates On Demand: Tailor the template to your project. Add details like what work needs to be done, the materials you'll use, and how much the client will pay. You can even make it look professional by adding your logo or a custom cover.
Send with a Click: Forget printing, scanning, and mailing. Securely send contracts electronically!
Electronic Signatures: Get them signed with electronic signatures by all parties from anywhere.
Easy Tracking: Monitor the status of every contract at a glance. No more wondering when someone's viewed or signed your document.
Payments Made Easy: Streamline your finances! Integrate payment solutions directly with Butterscotch. Collect deposits and payments electronically, keeping your cash flow flowing smoothly.
Centralized Storage: All your documents are securely stored in one digital location, accessible anytime, anywhere.

Think of a flooring contract as your project's secret weapon that helps things run like a dream. Butterscotch is like your personal contract assistant, streamlining the process and saving you from headaches.

Butterscotch Contracts